52. 252-2 Clauses Incorporated by Reference. (Feb 1998)

Download 281.02 Kb.
Name52. 252-2 Clauses Incorporated by Reference. (Feb 1998)
A typeDocumentation
  1   2   3   4   5

Clauses/Provisions RFP F13PS00047

52.252-2 Clauses Incorporated by Reference. (FEB 1998)
This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically from google search engine under Federal Acquisition Regulations (FAR).

52.203-3 Gratuities. (APR 1984)

52.203-5 Covenant Against Contingent Fees. (APR 1984)

52.203-7 Anti-Kickback Procedures. (OCT 2010)

52.203-11 Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. (SEP 2007)

52.203-12 Limitation on Payments to Influence Certain Federal Transactions. (OCT 2010)

52.203-14 Display of Hotline Poster(s). (DEC 2007)

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper. (May 2011)

52.204-7 Central Contractor Registration. (APR 2008)

52.204-8 Annual Representations and Certifications. (NOV 2011)

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. (JUL 2010)

52.209-5 Certification Regarding Responsibility Matters. (APR 2010)

52.209-6 Protecting the Government's Interest When Subcontracting with Contractors Debarred, )

Suspended, or Proposed for Debarment. (DEC 2010

52.215-2 Audit and Records - Negotiation. (OCT 2010)

52.219-14 Limitations on Subcontracting. (NOV 2011)

52.222-1 Notice to the Government of Labor Disputes. (FEB 1997)

52.222-3 Convict Labor. (JUN 2003)

52.222-4 Contract Work Hours and Safety Standards Act - Overtime Compensation. (JUL 2005)

52.222-6 Davis-Bacon Act. (JUL 2005)

52.222-7 Withholding of Funds. (FEB 1988)

52.222-8 Payrolls and Basic Records. (JUN 2010)

52.222-9 Apprentices and Trainees. (JUL 2005)

52.222-10 Compliance with Copeland Act Requirements. (FEB 1988)

52.222-11 Subcontracts (Labor Standards). (JUL 2005)

52.222-12 Contract Termination - Debarment. (FEB 1988)

52.222-13 Compliance with Davis-Bacon and Related Act Regulations. (FEB 1988)

52.222-14 Disputes Concerning Labor Standards. (FEB 1988)

52.222-15 Certification of Eligibility. (FEB 1988)

52.222-21 Prohibition of Segregated Facilities. (FEB 1999)

52.222-26 Equal Opportunity. (MAR 2007)

52.222-35 Equal Opportunity for Veterans. (SEP 2010)

52.222-36 Affirmative Action for Workers with Disabilities. (OCT 2010)

52.222-37 Employment Reports on Special Disabled Veterans, Veterans of the Vietnam

Era, and Other Eligible Veterans. (SEP 2006)

52.222-50 Combating Trafficking in Persons. (FEB 2009)

52.222-54 Employment Eligibility Verification. (JAN 2009)

52.223-3 Hazardous Material Identification and Material Safety Data. (JAN 1997)

52.223-5 Pollution Prevention and Right-to-Know Information. (MAY 2011)

52.223-6 Drug-Free Workplace. (MAY 2001)

52.223-14 RESERVED.

52.223-17 Affirmative Procurement of EPA-designated Items in Service and Construction Contracts. (MAY 2008)

52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. (AUG 2011)

52.225-13 Restrictions on Certain Foreign Purchases. (JUN 2008) \

52.225-21 Required Use of American Iron, Steel, and Manufactured Goods-

-Buy American Act--Construction Materials. (OCT 2010)

52.225-22 Notice of Required Use of American Iron, Steel, and Manufactured Goods--

Buy American Act--Construction Materials. (OCT 2010)

52.225-25 Prohibition on Contracting with Entities Engaging in Sanctioned Activities

Relating to Iran--Representation and Certification. (NOV 2011)

52.227-1 Authorization and Consent. (DEC 2007)

52.227-4 Patent Indemnity--Construction Contracts. (DEC 2007)

.52.228-2 Additional Bond Security. (OCT 1997)

52.228-5 Insurance - Work on a Government Installation. (JAN 1997)

52.228-11 Pledges of Assets. (SEP 2009)

52.228-13 Alternative Payment Protections. (JUL 2000)

52.228-14 Irrevocable Letter of Credit. (DEC 1999)

52.229-3 Federal, State, and Local Taxes. (APR 2003)

52.232-17 Interest. (OCT 2010)

52.232-23 Assignment of Claims. (JAN 1986)

52.232-33 Payment by Electronic Funds Transfer - Central Contractor Registration. (OCT 2003)

52.233-1 Disputes. (JUL 2002)

52.233-1 Disputes. (JUL 2002) - Alternate I (DEC 1991)

52.233-3 Protest after Award. (AUG 1996)

52.233-4 Applicable Law for Breach of Contract Claim. (OCT 2004)

52.236-7 Permits and Responsibilities. (NOV 1991)

52.236-8 Other Contracts. (APR 1984)

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements. (APR 1984)

52.236-10 Operations and Storage Areas. (APR 1984)

52.236-11 Use and Possession Prior to Completion. (APR 1984)

52.236-13 Accident Prevention. (NOV 1991)

52.236-14 Availability and Use of Utility Services. (APR 1984)

52.236-17 Layout of Work. (APR 1984)

52.242-13 Bankruptcy. (JUL 1995)

52.242-14 Suspension of Work. (APR 1984)

52.244-6 Subcontracts for Commercial Items. (DEC 2010)

52.249-2 Termination for Convenience of the Government (Fixed-Price). (MAY 2004) - Alternate I (SEP 1996)

52.249-10 Default (Fixed-Price Construction). (APR 1984)

52.252-6 Authorized Deviations in Clauses. (APR 1984)

1452.228-74 INDEMNIFICATION (NOV 2007)


DIAPR 2000 Non-Discrimination Notice to U.S. Department of the Interior Contractors, Subcontractors and Lessors


Section B--Supplies or Services/Prices
Prices on the SF-1442 and submit with offer.

Section C--Description/Specifications

The specifications and drawings and any modifications thereto attached to this contract as an attachment in Section J are by this reference made a part of this contract.

Section D--Packaging and Marking
(No Clauses)

Section E--Inspection and Acceptance

52.236-5 Material and Workmanship. (APR 1984)
(a) All equipment, material, and articles incorporated into the work covered by this contract shall be new and of the most suitable grade for the purpose intended, unless otherwise specifically provided in this contract. References in the specifications to equipment, material, articles, or patented processes by trade name, make, or catalog number, shall be regarded as establishing a standard of quality and shall not be construed as limiting competition. The Contractor may, at its option, use any equipment, material, article, or process that, in the judgment of the Contracting Officer, is equal to that named in the specifications, unless otherwise specifically provided in this contract.
(b) The Contractor shall obtain the Contracting Officer's approval of the machinery and mechanical and other equipment to be incorporated into the work. When requesting approval, the Contractor shall furnish to the Contracting Officer the name of the manufacturer, the model number, and other information concerning the performance, capacity, nature, and rating of the machinery and mechanical and other equipment. When required by this contract or by the Contracting Officer, the Contractor shall also obtain the Contracting Officer's approval of the material or articles which the Contractor contemplates incorporating into the work. When requesting approval, the Contractor shall provide full information concerning the material or articles. When directed to do so, the Contractor shall submit samples for approval at the Contractor's expense, with all shipping charges prepaid. Machinery, equipment, material, and articles that do not have the required approval shall be installed or used at the risk of subsequent rejection.
(c) All work under this contract shall be performed in a skillful and workmanlike manner. The Contracting Officer may require, in writing, that the Contractor remove from the work any employee the Contracting Officer deems incompetent, careless, or otherwise objectionable.
(End of clause)

52.246-12 Inspection of Construction. (APR 1996)
(a) Definition. Work includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.
(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.
(c) Government inspections and tests are for the sole benefit of the Government and do not -
(1) Relieve the Contractor of responsibility for providing adequate quality control measures;
(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;
(3) Constitute or imply acceptance; or
(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.
(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer's written authorization.
(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.
(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.
(g) If the Contractor does not promptly replace or correct rejected work, the Government may -
(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or
(2) Terminate for default the Contractor's right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.
(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government's rights under any warranty or guarantee.
(End of clause)

1452.236-80 Government Inspector
(a) Day-to-day inspection activities will be performed by the Contracting Officer's Representative (COR) or the Governments Contracted Site Inspector (GCSI) in the event that the COTR or GCSI are not present during the first hour of work at the beginning of the work day, the Contractor will immediately notify the Contracting Officer or the COR.
(End of clause)
52.246-21 Warranty of Construction. (MAR 1994)
(a) In addition to any other warranties in this contract, the Contractor warrants, except as provided in paragraph (i) of this clause, that work performed under this contract conforms to the contract requirements and is free of any defect in equipment, material, or design furnished, or workmanship performed by the Contractor or any subcontractor or supplier at any tier.
(b) This warranty shall continue for a period of 1 year from the date of final acceptance of the work. If the Government takes possession of any part of the work before final acceptance, this warranty shall continue for a period of 1 year from the date the Government takes possession.
(c) The Contractor shall remedy at the Contractor's expense any failure to conform, or any defect. In addition, the Contractor shall remedy at the Contractor's expense any damage to Government-owned or controlled real or personal property, when that damage is the result of -
(1) The Contractor's failure to conform to contract requirements; or
(2) Any defect of equipment, material, workmanship, or design furnished.
(d) The Contractor shall restore any work damaged in fulfilling the terms and conditions of this clause. The Contractor's warranty with respect to work repaired or replaced will run for 1 year from the date of repair or replacement.
(e) The Contracting Officer shall notify the Contractor, in writing, within a reasonable time after the discovery of any failure, defect, or damage.
(f) If the Contractor fails to remedy any failure, defect, or damage within a reasonable time after receipt of notice, the Government shall have the right to replace, repair, or otherwise remedy the failure, defect, or damage at the Contractor's expense.
(g) With respect to all warranties, express or implied, from subcontractors, manufacturers, or suppliers for work performed and materials furnished under this contract, the Contractor shall -
(1) Obtain all warranties that would be given in normal commercial practice;
(2) Require all warranties to be executed, in writing, for the benefit of the Government, if directed by the Contracting Officer; and
(3) Enforce all warranties for the benefit of the Government, if directed by the Contracting Officer.
(h) In the event the Contractor's warranty under paragraph (b) of this clause has expired, the Government may bring suit at its expense to enforce a subcontractor's, manufacturer's, or supplier's warranty.
(i) Unless a defect is caused by the negligence of the Contractor or subcontractor or supplier at any tier, the Contractor shall not be liable for the repair of any defects of material or design furnished by the Government nor for the repair of any damage that results from any defect in Government-furnished material or design.
(j) This warranty shall not limit the Government's rights under the Inspection and Acceptance clause of this contract with respect to latent defects, gross mistakes, or fraud.
(End of clause)

Section F--Deliveries or Performance


  1. To Schedule a Site Visit Contact Amber Zimmerman at 580-664-2205

52.215-8 Order of Precedence - Uniform Contract Format. (OCT 1997)
Any inconsistency in this solicitation or contract shall be resolved by giving precedence in the following order:

(a) The Schedule (excluding the specifications).
(b) Representations and other instructions.
(c) Contract clauses.
(d) Other documents, exhibits, and attachments.
(e) The specifications.
(End of clause)
52.236-1 Performance of Work by the Contractor. (APR 1984)
The Contractor shall perform on the site, and with its own organization, work equivalent to at least not less than 12 percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.
(End of clause)
52.236-6 Superintendence by the Contractor. (APR 1984)
At all times during performance of this contract and until the work is completed and accepted, the Contractor shall directly superintend the work or assign and have on the worksite a competent superintendent who is satisfactory to the Contracting Officer and has authority to act for the Contractor.
(End of clause)
52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984) - Alternate I (APR 1984)
The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to Proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than [90 Days from issuance of the Notice to Proceed] The time stated for completion shall include final cleanup of the premises.
(End of clause)
1452.211-71 CONTRACT WORK HOURS (NOV 2007)
The performance period established for this contract is based upon all work being conducted during regular working hours. Regular working hours are limited to the time between 7:30 Am and 4:00 PM, Monday through Friday, excluding Government holidays. If the Contractor desires to carry on work outside regular hours, including Saturdays, Sundays, and Government holidays, a request must be submitted to the Contracting Officer Representative in sufficient time to allow satisfactory arrangements to be made by the Government for access to the work site and inspection.
(End of Clause)

52.211-18 Variation in Estimated Quantity. (APR 1984)
If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.
(End of clause)
52.242-17 Government Delay of Work. (APR 1984)
(a) If the performance of all or any part of the work of this contract is delayed or interrupted
(1) by an act of the Contracting Officer in the administration of this contract that is not expressly or impliedly authorized by this contract, or
(2) by a failure of the Contracting Officer to act within the time specified in this contract, or within a reasonable time if not specified, an adjustment (excluding profit) shall be made for any increase in the cost of performance of this contract caused by the delay or interruption and the contract shall be modified in writing accordingly. Adjustment shall also be made in the delivery or performance dates and any other contractual term or condition affected by the delay or interruption. However, no adjustment shall be made under this clause for any delay or interruption to the extent that performance would have been delayed or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an adjustment is provided or excluded under any other term or condition of this contract.
(b) A claim under this clause shall not be allowed -
(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved; and
(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the delay or interruption, but not later than the day of final payment under the contract.
(End of clause)

Section G--Contract Administration Data

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.
(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) and Construction Inspector (CI), as required, at time of award. The COR and CI will be responsible for technical monitoring of the contractor's performance and deliveries. The COR and CI will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.
(c) The COR and CI are not authorized to perform, formally or informally, any of the following actions:
(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;
(2) Waive or agree to modification of the delivery schedule;
(3) Make any final decision on any contract matter subject to the Disputes Clause;
(4) Terminate, for any reason, the Contractor's right to

(5) Obligate in any way, the payment of money by the Government.
(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum.
The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR or CI has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's or CI's appointment, within 3 days of the occurrence.
Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.
(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph

(d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.
(f) The Contractor shall provide copies of all correspondence to the Contracting Officer, COR and CI.
(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR or CI acting within his or her appointment, shall be at the Contractor's risk.
(End of clause)
  1   2   3   4   5

Share in:


52. 252-2 Clauses Incorporated by Reference. (Feb 1998) iconThe name of the society is “The Royal New Zealand Foundation of the...

52. 252-2 Clauses Incorporated by Reference. (Feb 1998) icon1998 wl 1043831 (ca (Civ Div)), [1998] 4 All E. R. 476, [1999] E....

52. 252-2 Clauses Incorporated by Reference. (Feb 1998) iconPhrases and Clauses. Determine which of the following groups of words...

52. 252-2 Clauses Incorporated by Reference. (Feb 1998) iconInvesting in our ordinary shares involves a high degree of risk....

52. 252-2 Clauses Incorporated by Reference. (Feb 1998) iconAppendix crown Agents’ Reference: Enter ca ref Contractor’s Reference

52. 252-2 Clauses Incorporated by Reference. (Feb 1998) iconHas used your name as a reference on his Eagle Scout Rank Application....

52. 252-2 Clauses Incorporated by Reference. (Feb 1998) iconArticle 1: Preamble and General Clauses

52. 252-2 Clauses Incorporated by Reference. (Feb 1998) iconHomework for Feb. 14 (following my Guidelines)

52. 252-2 Clauses Incorporated by Reference. (Feb 1998) iconW58rgz-12-c-0011 Expanded Text Clauses

52. 252-2 Clauses Incorporated by Reference. (Feb 1998) iconW58rgz-13-c-0016 Expanded Text Clauses

forms and shapes

When copying material provide a link © 2017